HomeMy WebLinkAbout2011-013-1406 - Agreement with Xavier Cortada
City of Miami Gardens Agenda Cover Memo Council Meeting Date: January 26, 2011 Item Type: (Enter X in box) Resolution Ordinance Other X Fiscal Impact: (Enter X in box) Yes No Ordinance
Reading: (Enter X in box) 1st Reading 2nd Reading X Public Hearing: (Enter X in box) Yes No Yes No Funding Source: Miami Dade County Building Better Communities General Obligation Bond
Advertising Requirement: (Enter X in box) Yes No X Contract/P.O. Required: (Enter X in box) Yes No RFP/RFQ/Bid #: Miami Dade County Call to Artists X Strategic Plan Related (Enter X
in box) Yes No Strategic Plan Priority Area: Enhance Organizational Bus. & Economic Dev Public Safety Quality of Education Qual. of Life & City Image Communication Strategic Plan Obj./Strategy:
(list the specific objective/strategy this item will address) NA X Sponsor Name City Manager Danny Crew Department: Capital Improvement Projects Short Title: A RESOLUTION OF THE CITY
COUNCIL OF THE CITY OF MIAMI GARDENS, FLORIDA AUTHORIZING THE CITY MANAGER TO NEGOTIATE AND EXECUTE AN AGREEMENT WITH XAVIER CORTADA IN AN AMOUNT OF ONE HUNDRED FIFTY‐TWO THOUSAND DOLLARS
($152,000) TO IMPLEMENT THE PUBLIC ART DESIGN CONCEPT TITLED “SPLASH” FOR THE BETTY T. FERGUSON RECREATIONAL COMPLEX; PROVIDING FOR THE ADOPTION OF REPRESENTATIONS; PROVIDING AN EFFECTIVE
DATE. Staff Summary: Background In accordance with Miami‐Dade County Ordinance No. 2‐11.15 Art in Public Places, as well as the Building Better Communities General Obligation Bond (GOB)
contract for the Betty T. Ferguson Recreational Complex, the City must allocate 1.5% ($172,139) of the eligible project construction and design costs to integrate public art at the facility.
ITEM K-3) CONSENT AGENDA RESOLUTION Agreement w/Xavier Cortada
1515 NW 167 Street, Building 5 Suite 200 Miami Gardens, Florida 33169 On January 13, 2010 Council passed Resolution No. 2010‐009‐1191, which allowed payment of $8,000 to Miami‐Dade County
Art in Public Places Division to assist city staff in advertisement and selection of artist and proposed work of art to be implemented at the Betty T. Ferguson Recreational Complex for
recommendation to the City’s Mayor and Council. After payment to Miami‐Dade County Art in Public Places Division, along with $4,924 set aside for long‐term maintenance of the artwork,
$159,215 remained from the original allocation. All of the funding for this project is included in a current GOB contract between Miami‐Dade County and the City of Miami Gardens. Please
note that all future Art in Public Places projects will be fully managed by the City of Miami Gardens per City Ordinance 2010‐22‐230 established in July 2010. Current Situation A Call
to Artists for this project was placed on Miami Dade County Café system on June 24, 2010. City staff conducted a site visit of the Recreational Complex on July 7, 2010. Forty (40) applications
were received by July 23, 2010. On September 17, 2010, City staff met with Miami‐Dade County’s Art in Public Places Trust (Trust) to short list the applicants. On November 18, 2010,
the five shortlisted artists were paid $750 each (for a total of $3750 spent from allocation) in honorariums to prepare and present design concept proposals to Trust and City staff.
After much consideration, Xavier Cortada’s design concept proposal entitled “Splash” was chosen to be recommended to City Council for final approval to implement his work of art at the
Betty T. Ferguson Recreational Complex. The proposals from the five shortlisted artists are available for review at the Assistant to the Mayor and Council’s office. If approved, Xavier
Cortada will be compensated $152,000 to implement his artwork “Splash”, to serve as a functional, visual piece of art in the indoor pool area of the Betty T. Ferguson Recreational Complex.
The remaining $3,465 from the original allocation will serve as contingency for construction of this project. Proposed Action: In order to receive reimbursement of contracted Building
Better Communities General Obligation Bond funds and remain in compliance with Miami Dade County Ordinance No. 2‐11.15, it is recommended that the City Council authorize the City Manager
to negotiate and commission the services of Professional Artist Xavier Cortada in the amount of $152,000 to implement the public art design concept titled “Splash” at the Betty T. Ferguson
Recreational Complex. Attachment: Attachment A –Design Concept Proposal presented by Xavier Cortada Attachment B – Final Artist Phase‐Two Commission Contract
1 PROFESSIONAL ARTIST SERVICES AGREEMENT BETWEEN CITY OF MIAMI GARDENS AND XAVIER CORTADA, INC. FOR PHASE I – DESIGN SERVICES & PHASE II – FABRICATION & INSTALLATION SERVICES FOR THE
BETTY T. FERGUSON RECREATIONAL COMPLEX – AQUATIC CENTER THIS PROFESSIONAL ARTIST SERVICES AGREEMENT FOR PHASE – I DESIGN SERVICES AND PHASE II – FABRICATION & INSTALLATION SERVICES “Agreement”),
is made and entered into this day of , 2010, by and between the City of Miami Gardens and hereinafter referred to as the "City," and Xavier Cortada, Inc. hereinafter referred to as the
"Artist." WITNESSETH: WHEREAS, the City is implementing a public art program as set forth in Section 2-11.15 of the Code of Miami-Dade County, allocating certain funds for the acquisition
of art works for public places and authorizing the Miami-Dade County Art in Public Places Trust, hereinafter referred to as the “Trust,” to approve the selection of artists and make
payments for the design, fabrication and installation of works of art; and WHEREAS, funds funds for art have been allocated in accordance with Section 2-11.15 of the Code of Miami-Dade
County from City of Miami Gardens Funds; and procedures duly adopted by the County; and WHEREAS, the Artist was selected for the Betty T. Ferguson Recreational Complex – Aquatic Center
Project by the Trust through procedures duly adopted by the City under City Resolution No. 2010-09-1191; and WHEREAS, the Artist is commissioned for the Betty T. Ferguson Recreational
Complex – Aquatic Center Project by the City through procedures duly adopted by the City under City Resolution No. 2011-XX-XXXX, approving a Contract with the Artist as set forth herein;
WHEREAS, both parties wish the integrity and clarity of the Artist's ideas in the proposed work of art to be maintained; NOW THEREFORE, in consideration of the premises and the mutual
covenants herein contained, the parties agree as follows:
2 DEFINITIONS WORDS AND TERMS The words and terms as used in this Agreement shall have the following meanings unless some other meaning is plainly and clearly set forth. Architect "Architect"
means the Architect of Record and Primary Design Architectural Firm of CPZ Archtiects, Inc., 4316 West Broward Blvd., Plantation, FL 33317, contracted by the City of Miami Gardens for
the new Betty T. Ferguson Recreational Complex – Aquatic Center (the “Project”). Artist "Artist" means Xavier Cortada, Inc.. An essential and irrevocable condition of this agreement
is the direct involvement and responsibility of the Artist identified as “lead artist” for all creative and/or artistic related elements of the Work. Under no circumstances may such
responsibility be assigned and/or transferred to any other party. Construction Manager at Risk “Construction Manager at Risk” refers to N & J Construction, Inc, a business entity selected
and contracted by the City of Miami Gardens to implement the construction of the new Betty T. Ferguson Recreational Complex – Aquatic Center. Construction Project Team “Team” refers
to the collaborative forces of the Architect, Construction Manager at Risk, Miami-Dade County, City of Miami Gardens, and any of their related subcontractors. Consultants "Consultants"
means design, engineering or other professional consultants contracted by the City of Miami Gardens and/or the Architect or the Construction Manager at Risk as part of the Project team
with which the Artist may be required to interact for purposes of completing the Services as described in this Agreement. City "City" means City of Miami Gardens, Florida. County "County"
means Miami-Dade County, Florida. Director "Director" means the Director of the City of Miami Gardens Department of Capital Improvement Projects. The Director may designate a member(s)
of his staff for the purposes of working with the Artist on the Work. The authority of the Director described in this Contract will not be delegated to the designated staff person.
3 Phase II Services "Phase II Services" means those services, in whole or in part, as described under Article I, Section 1.1 and Section 1.3 of this Agreement. Schematic Design Documents,
Design Development Documents and Construction Documents “Schematic Design Documents,” “Design Development Documents” and "Construction Documents" means the Instruments of Service for
the design resolution and the fabrication and installation of the Work as described in Article I of this Agreement. Services "Services" means the Scope of Services described in Article
I of this Agreement. Site “Site” means the Betty T. Ferguson Recreational Complex located in the vicinity of at 3000 NW 199th St, Miami Gardens, FL 33056. Trust “Trust” means Miami-Dade
County Art in Public Places Trust. Work “Work” means the Approved Artist’s Proposal in its final format (Refer to Exhibit C), which complete concept includes a series of suspended artistic
acoustical panels for the 8,313 square foot indoor aquatic center, for which functionality and durability within a corrosive environment shall be of the upmost importance. The “L” shaped
pool, which features a bright yellow circular slide and 17’ soaring ceilings, will be utilized for recreational swimming and aquatic aerobics. It is imperative that the Artist work collaboratively
with a reputable manufacturer with indoor pool installation experience to implement the design and installation of the acoustical panel system. It is also preferred that the panel system
be installed predominately above the concrete deck area surrounding the edge of the pool for ease of installation and maintenance. The Artist may wish to consider the aesthetic qualities
of the MiMo influenced architecture of the center. Work Plan “Work Plan” refers to an Artist’s outline and schedule of proposed activities in sequential order describing the means and
methods proposed for completion of the Work in each of its phases, including the listing of potential subcontractors, vendors, and or fabricators hired by the Artist with their respective
relationship to the artwork project (Design /Fabrication /Installation.)
4 ARTICLE I SCOPE OF SERVICES 1.1 BASIC SERVICES -PHASE I Design The Artist shall perform all services, including travel, and furnish all supplies, materials and equipment as necessary
for the completion of the following specific tasks: 1.1.A) Schematic Design Documents -The Artist shall prepare a refined narrative (the "Artist's Proposal Statement") describing the
Artist’s design intent, drawings, models, graphic or other visual representation of the Work, together with such other data and graphic material as is necessary to portray the Site preparation
and permit the Director to assess its feasibility and compliance with applicable statutes and ordinances; and a preliminary project budget (the “Budget”) outlining “Probable Construction
Costs” for the fabrication, delivery, site preparation and installation of the Work (Exhibit C). The Budget will include applicable headings for all work to be performed by the Artist
and any work to be subcontracted by the Artist, as well as any specialty items such as mock-up samples and models anticipated by the Artist to be part of the costs to fabricate and install
the Work. The proposal shall be developed within a not-to-exceed budget of $152,000.00 which shall be inclusive of Services to be performed by the Artist, from Schematic Design and Design
Development through fabrication and installation. Documentation for the Schematic Design Phase of work shall include a listing of potential entities/vendors to be engaged by the Artist
and a preliminary breakdown of each proposed portion of their work. 1.1.B) Design Development Phase. The Artist shall perform Design Development services to include but not be limited
to the following: development of sketch models, research of structural and fabrication engineering requirements for compliance with applicable codes and standards and other related functional
attributes of the intended design (as may be applicable), research and determination of the types and sources of materials for the Work, development of prototypes, testing of mock-up(s)
if needed for verification of compliance with wind and stress tolerance requirements (all in accordance with the Florida Building Code and other applicable codes and standards), development
of a final presentation prototype or working model for review by the Director. In addition to the above-referenced services, the Artist shall, prior to completion of the Design Development
Phase, refine the Scope of the Work and complete a Budget Reconciliation Review and submit these written documents to the Director.
5 The Budget Reconciliation Review will include the drafting by the Artist of a Preliminary Working Budget detailing cost breakdowns for major components of the work, all in sufficient
form as to allow the Director to verify fiscal feasibility of the Work as refined under the Design Development Phase. Cost allocations shall be projected to a target completion date
of the Work to be mutually agreed upon by the Artist and the Director and Construction Project Team. The Preliminary Working Budget shall include an allocation for permit fees, the cost
of surety bonds (Refer to Exhibit D -Performance and Payment Bond) and Insurance in accordance with County requirements as described in Section 4.13. The Preliminary Working Budget shall
not exceed the total construction budget amount described in 1.2.E below, unless approved by the Director in writing. The Artist shall conduct research and recommend sources for materials
and/or fabricators for the Work, all in sufficient form to allow the Director to verify compliance with applicable codes and standards, and related longterm maintenance requirements
for each proposed design. Preliminary Material Samples shall be furnished and be subject to the Director’s approval prior to fabrication in an appropriate scale that allows the Director
to properly assess the aesthetic and workmanship quality intended of the finished product. The Artist may be requested to submit up to two (2) samples for each proposed fabrication material
and up to (1) sample for proposed technology-based elements of the Work, at no additional cost to the City, which materials will be retained by the City. As part of the Design Development
package the Artist shall develop a Maintenance Program Narrative. The Maintenance Program Narrative shall include a projected cost estimate for replacement parts of the Work (as may
be applicable), allowances for the Artist’s fee for maintenance (where applicable), and anticipated maintenance procedural requirements for no less than a ten (10) year period from completion
of the Work to ensure the proper care and upkeep of the Work. The Artist shall make recommendations based on the latest resources and technologies available at the time that the Maintenance
Program Narrative is drafted, with special attention to the logistics and fiscal constraints inherent in the facility where the artwork is to be located. Both parties hereto agree that
the Maintenance Program Narrative shall constitute a “working” maintenance plan and may be modified upon request by the Director during the construction phase. 1.1.C) Construction Documents
and Administration. Upon completion of the Design Development Phase described above, and upon notice to proceed by the Director, the Artist shall finalize Construction Documents for
the Work and be engaged in related construction administration activities to include but not be limited to the following: coordination with the
6 Construction Project Team’s architectural/engineering consultants hired for purposes of completing verification of logistical requirements with respect to architectural, structural,
electrical engineering considerations for the Site, and conducting site visits for coordination and planning with the Construction Project Team of construction phase of the Work. The
Artist will submit to the Director a detailed Budget the form outlined in 1.1.B. In addition, the Artist will submit a Schedule (“Project Schedule”) for fabrication and installation
of the Work that is coordinated with the Construction Project Team’s updated and approved construction schedule. All costs associated with this phase of work are inclusive in the Artist’s
Budget. 1.1.D) Construction Documents Format. The Work is to be incorporated into the building and the design is to include all documents by discipline as required by the Florida Building
Code to procure a permit to construct the Work from the Authorities Having Jurisdiction (AHJ) -City of Miami Gardens, Building Department. The Artist shall provide three (3) original
signed and sealed sets of architectural and engineering drawings, along with engineering calculations and other support documentation for the Work as may be applicable for the Artist
to process the plan review by the AHJ. All architectural, engineered drawings, and calculations shall be signed and sealed by appropriately licensed Florida architect (s) or engineer(s).
The Artist shall provide manufacturer’s product information, specifications, cut sheets, product warranty, material safety data sheets, etc. as may be appropriate to complete the submittals
package and inform the Director with respect to the nature and quality of materials being proposed by the Artist for the Work. 1.2 PROCEDURE – PHASE I Design The Artist shall determine/refine
the artistic expression, size, material, texture, color, location and method of fabrication of the Work, all subject to review and acceptance by the Director for compliance with the
City’s intent for the Project, any related project feasibility considerations as may be applicable, as provided below: 1.2.A) Promptly after the approval by the City of the Conceptual
Design Proposal, Work Plan, and preliminary project budget, the Artist shall meet with the Director and the Construction Project Team in order to coordinate the process and schedule
milestones for the completion of critical tasks and delivery of submittals pursuant to the Services to be performed under this Agreement. . 1.2.B) The Artist shall coordinate the completion
of the Services outlined in this Agreement with the schedule approved by Director, and shall complete the Instruments of Services for Phase I – Design on or before February 1, 2011.
7 1.2.C) All required submittals shall be delivered to the Director in sufficient form to allow for review, comments, and acceptance of the material. Submittals may be delivered for
preliminary review in an acceptable electronic format (PDF). All submittals are subject to review and comments by the Director, the Director’s designated staff, and the Construction
Project Team. 1.2.D) Timeframe for completing the review and acceptance of submittals is at the sole discretion of the Director. However, a reasonable time of 10 working days shall be
anticipated for completion of each required review. 1.2.E) The Artist shall, upon completion of the Services outlined in this Agreement and prior to final payment, submit to the Director
a Schedule which shall be coordinated with the Construction Project Team’s then current updated and approved construction schedule and finalized Budget of Probable Construction Costs
for the Work and negotiate an agreement for Phase II Services for the Work to include Fabrication, Installation and/or Construction Management Services, which total aggregate amount
shall not exceed $52,000.00. 1.2.F) The Artist shall, upon completion of the Services outlined in this Agreement and prior to final payment, submit proof to the Director, final releases
of claims from each of its subconsultants, subcontractors, vendors, and material suppliers, or a Consent of Surety that satisfies the requirements of Section 10-35 Code, Miami-Dade County,
Florida. 1.3 BASIC SERVICES – PHASE II Fabrication and Installation It is anticipated that based on the satisfactory completion of Phase I Design Services and notice of acceptance by
the Director, basic services for Phase II Fabrication and Installation may be negotiated by and between the Artist and the Director, including additional fee and costs as are appropriate.
Negotiations for Phase II Services may commence during performance of this Agreement or after the completion of the Services outlined herein, if mutually agreed upon in writing by the
Artist and the City. The Phase II negotiated services, if approved by the City, will be incorporated into this Agreement by form of an Amendment and/or Addendum as deemed appropriate
by the Director. The following Basic Services may be contracted in whole or in part as a result of the Director's acceptance of the Phase I Design Services and may be negotiated at a
later date: 1.3.A) Fabrication of the Work: when the Work is to be fabricated and installed by the Artist.
8 1.3.B) Construction Management Services: to include the on-site observation and monitoring of the progress, process, and quality of installation of the of the Work, when the Work is
to be installed under the Construction Manager at Risk contract, and which involves the Artist’s making periodic trips to the site to assist the Director and the Construction Project
Team in verifying compliance with the Construction Documents and the Artistic Design Intent as developed for the Work. 1.3.C) Installation: of special items or of the Work when deemed
by the Director as not able or desirable to be completed by any party other than the Artist. 1.3.D) Review and Approval: of Artist's design-related construction material samples, shop
drawings and/or other third party submissions for conformance with the Construction Documents and the Artist's Design Intent as developed for the Work. 1.3.E) Documentation & Reporting:
to include providing the Director and the Construction Project Team with field reports documenting site activity observed with any recommendations necessary to assure conformance to
Construction Documents and the Artist's Design Intent as developed for the Work. 1.3.F) Documentation of the Work. The Artist shall, upon installation of the Work and on or before submittal
of a final request for payment, deliver to the Director the following documentation of the Work for the City: 1.3.F.1) Two (2) CDs containing high resolution (image size not smaller
than 5x7 with a resolution of at least 300 dpi) and low resolution digital photographs ( 4x6 size at 100 dpi) of the completed Work, taken from at least three (3) different viewpoints,
for a total of no less than twelve (12) images; 1.3.F.2) Two (2) sets of at least four (4) different 8" x 10" color photographic prints that best represent the completed Work; 1.3.F.3)
Three (3) copies of each booklet, brochure, catalogue, print or invitation notice, if any, prepared by or at the direction and control of the Artist, pertaining to the Work performed
under the terms of this Agreement; and 1.3.F.4) One (1) full set of "as built" drawings as well as any and all construction, fabrication and installation specifications, drawings or
other documentation pertaining to the Work.
9 Electronic files and photographs shall be of acceptable professional quality in the determination of the Director and shall be properly marked. 1.4 PROCEDURE – PHASE II Fabrication
and Installation Authorization to proceed with Phase II is contingent upon successful completion of Phase I – Design and on the new Betty T. Ferguson Recreational Complex – Aquatic Center
project generating the funding for this artwork commission. Additional terms and conditions for Phase II Work may be incorporated into this Agreement via Amendment or Addendum as deemed
appropriate by the Director, and approved by the City, and as particularly described below: 1.4.A) Promptly after the execution of the Phase II Agreement, the Artist shall meet with
the Director, the Construction Project Team, and any other party related to the project to coordinate the fabrication and installation process and schedule milestones for the completion
of tasks pursuant to the Services to be performed under the Phase II Agreement. 1.4.B) The Artist Artist shall coordinate the completion of the Services outlined in the Phase II Agreement
with the Construction Project Team’s updated and approved construction schedule and shall update the Schedule for the Work in coordination with updates made by the Construction Project
Team to the construction schedule for the new Betty T. Ferguson Recreational Complex – Aquatic Center. The Artist shall submit to the Director for approval each updated Schedule for
the Work. 1.4.C) Immediately upon receipt of the Notice to Proceed for Phase II, the Artist shall begin fabrication of the Work to be completed and installed within the timeframe set
forth in the Schedule. 1.4.D) During the performance of Phase II Services, the Artist shall submit proof to the Director, of releases of claim for every progress payment made by the
Artist to his/her fabricators, contractors, and or any other entity hired by the Artist for purposes of completing the Work. The Artist shall fully comply with this requirement prior
to submittal of a a final payment request for services outlined in Phase II Agreement. ARTICLE II COMPENSATION 2.1 FIRM FIXED PRICE
10 The City shall pay the Artist a Fixed Fee (the "Artist’s Fixed Fee") for PHASE I -Design in the fixed fee amount of ONE HUNDRED THOUSAND DOLLARS & NO CENTS ($100,000) (the “Contract
Amount”). THE FIXED FEE SHALL CONSTITUTE FULL COMPENSATION FOR ALL SERVICES AND MATERIALS TO BE PERFORMED AND FURNISHED BY THE ARTIST UNDER THIS AGREEMENT, INCLUDING THE ARTIST'S FEE,
CONSULTING FEES, AND/OR ANY RELATED OVERHEAD EXPENSES AND TRAVEL. 2.2 METHOD OF PAYMENT 2.2.A) Artist's Fixed Fee for Design Development The City shall pay the Artist the Fixed Fee for
Design Development Services for the Work in the following installments: 2.2.A.1) $15,000 upon execution of this Agreement, completion of the Project Orientation Meeting, submittal of
the Work Plan and Preliminary Project Budget, verification and approval by the Director, and invoice by the Artist. 2.2.A.2) $20,000 upon Artist submittal to the Director of proof of
agreement with local A/E, and Notice to Proceed for A/E Design Services, verification and approval by the Director, and invoice by the Artist. 2.2.A.3) $25,000 upon the date that the
Artist submits to the Director a substantially complete set of Design Documents, verification and approval by the Director, and invoice by the Artist. 2.2.A.4) $20,000 upon the date
that the Artist notifies to the City the completion of 60% Construction Documents, submittal of documentation for verification and approval by the Director, and invoice by the Artist.
2.2.A.5) $20,000 upon the date that the Artist delivers to the City a complete and permittable Construction Document Set (as set forth in Section 1.1.D), verification and acceptance
by the Director, and invoice by the Artist. 2.2.B) Phase II – Fabrication & Installation Disbursement of payments due to the Artist for Phase II – Fabrication & Installation Services
shall be determined by the Director and the Artist upon completion and acceptance by the Director of Phase I – Design and incorporated herein as an
11 addendum (Phase II Payment Schedule Addendum), in accordance with applicable provisions set forth in this Agreement. The Artist’s Fee for Phase II shall be negotiated by the Artist
and the Director subject to the finalized scope of services submitted by the Artist and approved by the Director and incorporated as an addendum to this Agreement. The Director reserves
the right to either itemize fees payable under Phase II or issue the Addendum based on a lump sum amount, which cumulative amount shall not exceed the Contract Amount stipulated under
Section 1.2.E above. The Artist shall be responsible for procuring the services of a licensed subcontractor to procure all necessary permits, bonding and insurance as needed for any
of the Work. Eligibility for payment shall be subject to verification by the Director that each stage has been completed in accordance with this Agreement. ARTICLE III TIME OF PERFORMANCE
3.1 DURATION The Services to
be required of the Artist as set forth in Article I, Scope of Services, shall commence upon the execution of this Agreement and shall be completed and installed in adherence with the
Schedule for completion of the Work and in coordination with the construction schedule established and maintained by the Construction Project Team for the new Betty T. Ferguson Recreational
Complex – Aquatic Center. It is the Artist’s explicit responsibility to monitor and coordinate all aspects of scheduling in conjunction with the Construction Project Team. Discrepancies
in scheduling that may result in Artist’s claims for extension of time and/or additional compensation must be documented pursuant to Section 4.17 of this Agreement. Receipt by the Artist
of a fully executed copy of this Agreement shall constitute the Notice to Proceed with the Work as outlined in this Agreement. 3.2 CONSTRUCTION DELAYS In the event that the Artist completes
fabrication or procurement of the Work in accordance with the above-referenced Schedule and is delayed from installing it on or before the time specified in in the Schedule as a result
of the construction of the Site not being sufficiently complete to reasonably permit installation of the Work therein, the Artist shall be reimbursed for reasonable storage costs and
any additional compensation related to the delay, incurred for the period between the time specified in the Schedule for installation and the date upon which construction of the Site
is sufficiently complete to reasonably permit installation of the Work. All Artist’s delay claims seeking additional compensation must be documented to the Director’s satisfaction pursuant
to Section 4.17 of this Agreement.
12 3.3 EARLY COMPLETION OF THE ARTIST SERVICES In the event that the Artist completes Services as set forth in Article I prior to the time specified in the Schedule for installation,
and, as a result thereof, incurs storage costs, the Artist shall bear the full cost of such storage. 3.4 DELAY BY ARTIST In the event the Artist causes a delay that impacts the construction
schedule, the Artist shall have the duty to accelerate his services to mitigate the delay at no additional cost to the City. If the Artist is unable to mitigate the delay in an acceptable
and effective manner, the Director may terminate this Agreement pursuant to Section 4.6.B of this Agreement. ARTICLE IV GENERAL CONDITIONS-PHASE I & II 4.1 OWNERSHIP OF INSTRUMENTS OF
SERVICE Upon completion of the Services, all design materials including but not limited to renderings, models, mock ups, plans, samples and other documentation as outlined under Section
1.3.F, developed by the Artist and delivered to the Director for the purpose of this Agreement, shall become the property of the City. All material data and documentation as described
herein shall be delivered to the Director prior to completion of the Agreement and final payment to the Artist. The Artist shall retain sole ownership of the copyright to the Work. The
City reserves the right to appropriate use of all material data and documentation for public exhibition, publication, and or recordkeeping purposes of the City. 4.2 TIME EXTENSIONS A
reasonable extension of contract time, at no additional cost to the City, will be granted by the Director in the event there is a delay on the part of the Construction Project Team or
should conditions beyond the Artist's control or Acts of God render performance of its duties impossible. Where such conditions arise, the Artist shall so notify the Director in writing
with an explanation describing the circumstances that do not permit him/her to complete the Services as described in this Agreement in the time allotted. In such event, the parties hereto
understand and agree that the Director shall be the sole judge of what constitutes "beyond the Artist's control". An Artist’s claim for a compensable time extension shall follow the
procedures outlined under Section 4.17 of this Agreement. 4.3 WARRANTY OF ORIGINALITY The Artist warrants that the tangible objects it delivers to the City in the performance of this
Agreement shall be the result of the artistic efforts of the Artist and that, unless otherwise stipulated, the Work shall be unique and an
13 edition of one. The Artist shall not reproduce in any scale this Work and or a substantially similar Work without the Director’s explicit written consent. 4.4 ASSIGNMENT, TRANSFER
OR SUBCONTRACTING A material element of this Agreement is the personal skill, judgment and creativity of the lead Artist. Therefore, the Artist shall not assign, transfer or subcontract
the creative and artistic portions of the Work to another party without the prior written approval of the Director. 4.5 INDEPENDENT CONTRACTOR The Artist is an independent contractor
and nothing in this Agreement shall be construed as constituting the Artist an employee, agent or representative of the City. Any employee of the City shall not supervise the Artist,
nor shall the Artist exercise supervision over any employee or officials of the City. There are no third party beneficiaries to this Agreement. 4.6 TERMINATION AND SUSPENSION OF SERVICES
The services to be performed under this Agreement may be terminated by either party, subject to written notice submitted thirty (30) days from termination, provided that attempts to
reconcile the reason for termination have been undertaken but failed. The notice shall specify whether the termination is for convenience or cause. 4.6.A) Termination for Convenience
4.6.A.1) If termination for convenience by the City, the Artist shall have an equitable adjustment in the fee (without allowance for an anticipated profit on unperformed services) in
which event the City shall have the right at its discretion to possession and transfer of title to the sketches, design, and models already produced and submitted or produced for submission
by the Artist under this Agreement prior to the date of termination, provided that no right to fabricate or execute the Work shall pass to the City. 4.6.A.2) If termination for convenience
by the Artist, the Artist shall remit to the City a sum equal to all payments (if any) made to the Artist pursuant to this Agreement prior to termination. The City shall revert title
of the Work to the Artist and return any material data and or work in progress to the extent that such return does not impact City property. 4.6.B.) Termination for Cause If either party
to this Agreement shall willfully or negligently fail to fulfill in a timely and proper manner, or otherwise violate, any of the
14 covenants, agreements or stipulations material to this Agreement, the other party shall thereupon have the right to terminate this Agreement by giving written notice to the defaulting
party of its intent to terminate specifying the grounds for termination. The defaulting party shall have thirty (30) days after receipt of the notice to cure the default. If it is not
cured, then this Agreement shall terminate. 4.6.B.1) If default by the City, the City shall promptly compensate the Artist for all services properly performed by the Artist prior to
termination. 4.6.B.2) If default by the Artist, all finished and unfinished drawings, sketches, photographs, maquettes, prototypes, or other work products prepared and submitted by the
Artist under this Agreement shall at the City’s option become its property, provided that no right to fabricate and or execute the Work shall pass to the City. The City shall promptly
compensate the Artist for all services performed satisfactorily by the Artist prior to termination. 4.6.B.3) Notwithstanding any of these conditions, the Artist shall not be relieved
of liability to the City for damages sustained by the City by virtue of any breach of this Agreement by the Artist, and the City may reasonably withhold payments to the Artist until
such time as the exact amount of such damages due the City from the Artist are determined. 4.6.C.) Suspension of Services The Director may at any time suspend this Agreement for a period
not exceeding one hundred twenty (120) days or such further period to which the parties may agree, by giving written notice to the Artist of such suspension, which all shall become effective
upon receipt by the Artist of the written suspension notice. An equitable adjustment shall be made in the time of performance of the Services, and the Agreement shall be modified accordingly,
if the suspension results in an increase in the time required for performance of the Services and compensation payable to the Artist under Article II shall be modified in accordance
with costs, if any, as demonstrated and documented pursuant to Section 4.17 by the Artist to result directly from such suspension. 4.7 PUBLICITY AND NEWS RELEASES The Artist shall not
during the performance of this Agreement disseminate publicity or news releases regarding this project or the Services without prior written approval of the Director.
15 4.8 CODE COMPLIANCE All work shall be done in compliance with Florida Building Code. The approval of the structural acceptability of the artwork shall be determined in consultation
with the governing Authorities Having Jurisdiction (AHJ) – City of Miami Gardens Building Department officials to assure compatibility with all applicable statutes and regulations. 4.9
EQUAL EMPLOYMENT OPPORTUNITY AND NON-DISCRIMINATION In connection with the execution of this Agreement, the Artist shall not discriminate against employees or applicants for employment
because of race, religion, color, age, sex, ancestry, marital status, physical handicap, place of birth, sexual orientation, or national origin. The Artist shall take affirmative actions
to ensure that applicants are employed, and that employees are treated during their employment, without regard to their race, religion, color, sex, age, ancestry, marital status, physical
handicap, place of birth, sexual orientation, or national origin. Such actions shall include, include, but not be limited to the following: employment, upgrading, demotion, or transfer;
recruitment, or recruitment advertising; and selection for training, including apprenticeship. 4.10 ON SITE SUPERVISION The Artist will be personally involved in all phases of the Work's
development, fabrication and installation. The Artist shall be on site periodically during the time that the Work is being installed as required to ensure that the Work is being installed
in accordance with the Artist's Design Intent. 4.11 FINAL ACCEPTANCE When the Artist's Services have been completed, the Artist shall so advise the Director in writing. Within thirty
(30) days of receipt of such notice the Director shall give the Artist notice in writing of any services that have yet to be satisfactorily completed (“Punch List”.) Upon completion
of such Punch List services, the Artist shall notify the Director, and within thirty (30) days of receipt of such notice, the Director shall give the Artist written notice of final acceptance
or notice of the specified unfinished Punch List services. Final acceptance shall not constitute a waiver or abandonment of any rights or remedies available to the City under any other
section of this Agreement. 4.12 RISK OF LOSS The Artist shall bear the full risk of loss of or damage to the Work until the Services have been completed and the Work installed and accepted
by the Director. The Artist shall take such measures and precautions as are necessary to protect the Work from loss or damage. 4.13 INSURANCE Prior to commencement of Phase II – Fabrication
and Installation services, the Artist shall furnish or cause its Contractor to furnish to the City of Miami Gardens, c/o Department of Capital Improvement Projects, 1515 NW 167th Street,
#200,
16 Miami Gardens, Florida 33169, Certificate(s) of Insurance which indicate that insurance coverage has been obtained which meets the requirements as outlined below: A) Worker’s Compensation
Insurance for all employees as required by Florida Statute 440. B) Public Liability Insurance on a comprehensive basis in an amount not less than $500,000 combined single limit per occurrence
for bodily injury and property damage. City of Miami Gardens must be shown as an additional insured with respect to this coverage. C) Automobile Liability Insurance covering all owned,
non-owned and hired vehicles used in connection with the work, in an amount not less than $300,000 combined single limit per occurrence for bodily injury and property damage. D) Owner’s
Protective Liability Insurance-issued in the name of City of Miami Gardens as sole insured, in an amount as indicated in (B) above. This policy must be endorsed to indicate that any
premium whether deposit or final, shall be the sole obligation of the Artist and/or its Contractor. All insurance policies required above shall be issued by companies authorized to do
business under the laws of the State of Florida, with the following qualifications: The company must be rated no less than “B” as to management, and no less than “Class V” as to financial
strength, by the latest edition of Best’s Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey, or its equivalent, subject to the approval of the County Risk Management
Division. or The company must hold a valid Florida Certificate of Authority as shown in the latest “List of All Insurance Companies Authorized or Approved to Do Business in Florida”
issued by the State of Florida Department of Insurance and are members of the Florida Guaranty Fund. Certificates will indicate that no modification or change in insurance shall be made
without (30) days written advance notice to the Certificate Holder. 4.14 INDEMNITY
17 Except as specified in subparagraph 4.21(d) below, the terms of which shall govern and control, the Artist shall defend, indemnify and hold the City and its officers, employees, agents
and instrumentalities from any and all liability, losses and damages, including attorney’s fees and costs of defense, which the City or its officers, employees, agents or instrumentalities
may incur as a result of claims, demands, suits or causes of actions or proceedings of any kind of nature arising out of, relating to or resulting from the negligent performance or willful
misconduct of the Artist or its employees, agents, servants, partners, principals or subcontractors. The Artist shall pay all claims and losses in connection therewith and shall investigate
and defend all claims, suits or action of any kind or nature in the name of the City, where applicable, including appellate proceedings, and shall pay all costs, judgments and attorneys
fees which may issue thereon. The Artist expressly understands and agrees that any insurance protection required by this agreement or otherwise provided by the Artist shall in no way
limit the responsibility to indemnify, keep and save harmless and defend the City or its officers, employees, agents and instrumentalities as herein provided. 4.15 LISTING OF FIRST-TIER
SUBCONTRACTORS & MATERIAL SUPPLIERS Prior to ordering any material supplies or commencing fabrication of the Work, the Artist shall provide the Director a listing of all contractors
the Artist intends to hire for purposes of completing the Services of this Agreement and any material supplier sources the Artist intends to utilize for major components of the Work.
“Major Components” shall mean single source material purchases that represent twenty percent (20%) or more of the total estimated construction material costs for the Work as identified
in the Artist’s Statement of Probable Construction Cost. The Artist shall identify the type of work each first-tier subcontractor is to perform and the estimated value thereof. Upon
submittal of the list by the Artist and approval by the Director, the Artist shall not thereafter make any change to the approved list without prior written approval by the Director.
4.16 CHANGES/ADDITIONAL SERVICES The Artist and the City may, from time to time, agree on changes in the nature of or in the time of Services. Such agreement shall be in writing and
signed by both parties. The Director can act without further approval by the City if the cost and risk to the City are not affected. The Director shall act without approval of the City
to modify the Compensation Schedule provided that the total payments on the project do not exceed the stipulated amount under Section 2.1 and the Director receives a signed acceptance
from the Artist of the modified Payment Schedule. Any Services requested of the Artist by the City outside those outlined in the terms of this Agreement, or changes requested by the
City to the Work or the timetable for completion which materially expands the scope of work are considered Additional Services. The City and Artist agree to mutually assess any Additional
Services and equitably adjust the amount of compensation accordingly. The City retains the right for equitable credit, to be consistent with
18 the terms and conditions as described herein, for changes in the Work which result in a reduction of the scope of work as outlined in this Agreement. 4.17 CLAIMS FOR ADDITIONAL COMPENSATION
4.17.A) No claims for additional compensation, time extension or for any other relief under the Agreement shall be recognized, processed, or treated in any manner unless the same is
presented in accordance with this Article. Failure to present and process any claim in accordance with this Article shall be conclusively deemed a waiver, abandonment or relinquishment
of any such claim, it being expressly understood and agreed that the timely presentation of claims, in sufficient detail to allow proper investigation and prompt resolution thereof,
is essential to the administration of this Agreement. 4.17.B) Each and every claim shall be made in writing and delivered to the Director as soon as reasonably practicable after the
event, occurrence or non-occurrence which gives rise to such claim, however, in no event later than 10 days after the event or occurrence. Verbal, telephone or facsimile notice shall
be given in those instances where delay in presenting the claim would result in the conditions causing the claim to change, thereby requiring an immediate need to examine the job site
or other conditions to ascertain the nature of the claim before the condition(s) disappear or become unobservable. Any such oral or facsimile notice shall be followed, at the earliest
practicable time, but in no event more than 10 days after the event causing the claim, by written confirmation of the claim information 4.17.C) Each and every claim shall state: 4.17.C.1.
The date of the event or occurrence giving rise to the claim. In the case of a claim arising from a claimed nonperformance, the date when it is claimed that performance should have occurred
shall be stated. 4.17.C.2. The exact nature of the claim, including sufficient detail to identify the basis for the claim, including by way of example only, such detail as job site location,
affected trades, contract clauses relied upon, schedule references, correspondence or any other details reasonably necessary to state the claim 4.17.C.3. The claim shall clearly state
whether additional monies are part of the claim. If known, the dollar
19 value associated with the claim shall be stated. If unknown, the notice shall indicate the types of expenses, costs or other monetary items that are reasonably expected to be part
of the claim amount. 4.17.C.4. The claimed items of additional compensation shall be properly documented and supported with copies of invoices, time sheets, rental agreements, crew sheets
and the like. 4.17.C.5. Any claim for additional monies that also involves a request for an Agreement time extension shall be submitted together with the amount of time being requested
and the supporting data including applicable scheduling references supporting the claim. 4.17.C.6. No reservation of rights will be effective to preserve any claims that are not fully
documented and submitted in accordance with requirements of this Agreement. Failure of the Artist to make a specific reservation of rights regarding any such disputed amounts within
the Request for Partial Payment or the Request for Final Payment shall be construed as a waiver, abandonment and relinquishment of all claims for additional monies resulting from the
claim, 4.17.D) The currently approved schedule(s) for the Work shall be the basis for interpreting any and all time-associated provisions of the Agreement including proposed time extensions.
Proposed time extensions must include a time impact analysis (TIA), clearly showing the impact on the current schedule, and conclusively proving the validity of the proposed extension
4.17.E) Director and or his designee shall be allowed full and complete access to all personnel, documents, work sites or other information reasonably necessary to investigate any claim.
Within 60 days after a claim has been received, the claim shall either be recognized or if the claim is not recognized within 60 days it shall be deemed denied. If the claim is recognized,
the parties shall attempt to negotiate a satisfactory settlement of the claim, which settlement shall be included in a subsequent amendment and or addendum to this Agreement to be approved
by the City. If the parties fail to reach an agreement on a recognized claim, the City shall pay to the Artist the amount of money it deems reasonable to compensate the Artist for the
recognized claim.
20 4.17.F) The Artist shall not cease work on account of any denied claim or any recognized claim upon which an agreement cannot be reached. 4.17.G) With regard to any and all claims
for additional compensation resulting from delays to the Work, the Artist assumes all risk for the following items, none of which shall be the subject of any claim and none of which
shall be compensated for except as they may have been included in the compensation for indirect costs. (1) Home office expenses or any direct costs incurred (2) Loss of anticipated profits
on this or any other project (3) Loss of bonding capacity or capability (4) Losses due to other projects not bid on (5) Loss of business opportunities. (6) Loss of productivity on this
or any other project (7) Loss of interest income on funds not paid (8) Costs to prepare, negotiate or prosecute claims (9) Costs spent to achieve compliance with applicable laws and
ordinances 4.18 RIGHT OF DECISION All Services shall be performed by the Artist at the sole direction direction of and to the reasonable satisfaction of the Director who shall decide
all claims, questions or disputes concerning the prosecution and fulfillment of the Services hereunder, and the character, quality, amount and value thereof, and the Director's decisions
thereon shall be conclusive and binding upon the parties hereto unless such determination is clearly arbitrary or unreasonable. All decisions of the Director shall be written and transmitted,
pursuant to Section 4.19 to the Artist. In the event that the Artist does not concur in the judgments of the Director, the Artist shall present his written objections to the Department
of Capital Improvement Projects Assistant City Manager within thirty (30) days from the date of the Artist's receipt of such written decision. The Director and the Artist shall abide
by the decision of the Assistant City Manager. 4.19 NOTICES All communications relating to the day-to-day activities shall be exchanged between the Artist, or his authorized representative,
and the Director or authorized representative of the City. Such authorized representatives shall be designated in writing promptly upon commencement of the Services. Any notices, reports,
or other written communications from the Artist to the City shall be considered delivered when posted or delivered in person to the Director. Any notices, reports, or other communications
from the City to the Artist shall be considered delivered when posted to the Artist at the last address left on file with the City, or delivered in person to said Artist or his authorized
representative.
21 Until changed by notice in writing, all such notices and communications shall be addressed as follows: If to the City: If to the Artist: Brandan DeCaro, Director Xavier Cortada, Inc.
City of Miami Gardens, Department of Capital Improvement Projects 1515 NW 167th Street, #200 3621 SW 3rd Ave Miami Gardens, FL 33169 Miami, FL 33145 E-mail: cgoetzman @miamigardens-fl.gov
xavier@cortada.com 4.20 SURVIVING COVENANTS The covenants and obligations set forth in this Article IV, Section 4.20 shall survive the completion of installation of the Work and shall
continue for a period ending on the twentieth anniversary of the Artist's death. 4.20.A) Maintenance of the Work. The City recognizes that although normal maintenance of the Work will
involve simple and relatively inexpensive procedures, such maintenance on a regular basis is essential to the integrity and authenticity of the Work. The City shall assure such regular
maintenance according to the written specifications of the Artist, and shall protect and maintain the Work against the ravages of time, vandalism and the elements, and to the extent
practicable shall make all significant repairs and restorations of the Work in accordance with Section 4.20(E) below. 4.20.B) Notice. The City shall at its expense prepare and install
at the Site, pursuant to the written instructions and subsequent approval of the Artist, a tasteful public notice including the Artists' name, and shall maintain such notice in good
repair against the ravages of time, vandalism and the elements. 4.20.C) Permanent Record. Issuance of Final Payment for the Work shall indicate to the Artist the official acceptance
and adoption of provisions of this Article IV, Section 4.20 by the Miami-Dade Art in Public Places Trust. The Trust shall ensure that the City maintains in an appropriate place a permanent
record of this Agreement, such resolution and the location and history of the Work. 4.20.D) Alteration of the Site or of the Work. It is an inherent nature of any site to be vulnerable
to physical alterations of varying degrees that may arise out of a functional need consistent with its intended design and usage and/or the operational requirements of the Site.
22 Respectively, the integrity and authenticity of the Work may become compromised by an alteration of the Site if the Work is an integral component of the Site. It is with the express
understanding above that the Artist hereby agrees to waive all rights to monetary compensation for any acts arising out of operational requirements which may cause alterations to the
Site and/or the Work. The City shall notify the Artist of any proposed alteration of the Work or of the Site that would affect the intended character and appearance of the Work, and
shall consult with the Artist in the planning of any such alteration. If any such alteration of the Site or of the Work is made without the express written approval of the Artist, the
Artist may elect, upon a minimum forty-eight (48) hours written notice to the Director, to enter upon the Site and at the expense of the City remove or obliterate the public notice referred
to in Section 4.20(B) above, as well as any signature or other emblem identifying the Artist with the Work, and may take such other action as he/she may choose in order to disavow the
Work. 4.20.E) Repairs & Restorations of the Work. The City shall have the right to determine when and if repairs and restorations to the Work will be made. During the Artist's lifetime,
the Artist shall have the right to approve all repairs and restorations of a significant nature. If the Artist fails or refuses to approve any repair or restoration, the City shall have
the right to make such repair or restoration. To the extent practical, the Artist shall be given the opportunity to make or personally supervise significant repairs and restorations
and the Artist may, at the discretion of the City, be paid a reasonable fee for any such service, provided that both parties prior to the execution of such services mutually agree upon
the fee in writing. 4.20.F) Changes of Address. The Artist shall notify the City of changes of address and telephone/fax numbers, and his/her failure to do so, if such failure prevents
the City from from locating him/her, shall be deemed a waiver by the Artist of his/her rights to enforce those provisions of this Agreement that require the express approval of the Artist.
4.20.G) Copyright Transfer. The Artist shall notify the City of a transfer in the ownership of the copyright
and provide name, title, current address and telephone/fax numbers to the City in such event. Any transfer of copyright must carry with it the requirement for the City’s right to appropriate
use of all material data and documentation for public exhibition, publication, and or recordkeeping purposes of the City.
23 4.21 MISCELLANEOUS CONDITIONS 4.21.A) Project Coordination. The Artist and/or his subcontractor(s) will conduct their operations in coordination with the Construction Project Team
so as to minimize any impact on the progress of other work by others. The Artist and/or his subcontractor(s) may be required from time to time to attend site coordination meetings and
provide the Director upon request updated schedules for the Work. 4.21.B) Notice of Potential Project Delays and or Claims for Additional Compensation. The Artist shall notify the Director
in writing of any potential claims for construction delays and/or for additional compensation which may arise within the scope of this Agreement pursuant to the conditions set forth
in Section 4.17. Failure to do so shall constitute a waiver of the claim. 4.21.C) Site Inspections/Site Conditions/Staging Requirements. Prior to mobilization, the Artist and/or his
subcontractor(s) shall visit and inspect the Site. Subsequent to such inspection and throughout the course of the Work the Artist shall notify the Director of any storage, access, power,
water and other requirements for proper installation of the Work that are not to be provided by the Artist. The Artist shall notify the Director in writing of any adverse Site conditions
that may impede or otherwise impact the smooth and normal progress of the Work and which require resolution before proceeding with any portion of the Work. The Artist shall provide such
notice within a reasonable amount of time so as to allow the Director to properly coordinate with the field and not create any delays to the construction schedule. 4.21.D) Job Safety.
The Artist and/or his subcontractor(s) are responsible for compliance with OSHA and/or other Federal, State, County or City safety requirements and shall ensure said compliance is maintained
throughout the duration of the Work. 4.21.E) Restricted "Off" Work Hours. Where applicable, the Artist and/or his subcontractor(s) shall observe and comply with any Restricted "Off"
Work Hours requirements. Artist shall submit to the Director in writing any request(s) to perform work other than during "normal work hours" and said request shall be subject to approval
by the Construction Management Team. (THIS SPACE IS LEFT INTENTIONALLY BLANK)
24 4.22 ENTIRETY OF AGREEMENT This writing embodies the entire Agreement and understanding between the parties hereto, and there are no other agreements and understandings, oral or written,
with reference to the subject matter hereof that are not merged herein and superseded hereby. No alteration, change, or modification of the terms of the Agreement shall be valid unless
made in writing and signed by both parties hereto and approved by appropriate formal action of the City. This Agreement, regardless of where executed, shall be governed by and construed
according to the laws of the State of Florida. IN WITNESS WHEREOF the parties hereto have executed these presents this _____________ day of _______________________, 2010. ATTEST: RONETTA
TAYLOR, CMC CITY OF MIAMI GARDENS, FLORIDA BY: __________________ BY: _____________________ CITY CLERK CITY MANAGER ATTEST: BY: _____________________ ARTIST _____________________ WITNESS